Welcome to Concrete Surface Pros. By accessing or using our website or services, you agree to comply with and be bound by the following Terms and Conditions. Please read these terms carefully before using our services.

1. General Information

Concrete Surface Pros (“we,” “us,” “our”) provides concrete floor solutions, including residential coatings, commercial coatings, polished concrete, and other related services. These Terms and Conditions govern your use of our website and services and form a legally binding agreement between you and Concrete Surface Pros.

2. Services Provided

We offer a range of concrete floor solutions, including but not limited to:

• Residential Coatings
• Commercial Coatings
• Polished Concrete
• Epoxy, Polyurethane, and Quartz-Filled Coatings
• Concrete Floor Repair and Restoration

We reserve the right to modify, add, or remove services at any time without prior notice.

3. Use of Our Website

By using our website, you agree to:

• Provide accurate and complete information when requesting services or contacting us.
• Not engage in activities that may damage, disable, or interfere with the functioning of our website.
• Not use our website to transmit any harmful or illegal content.

4. Service Quotes and Pricing

• All quotes provided by Concrete Surface Pros are estimates and subject to change based on the scope of work and site conditions.
• Final pricing is determined upon assessment of the project site and upon agreement between both parties.
• We may adjust prices for services based on material costs, labor, and other factors.

5. Payment Terms

• Payments for services must be made according to the payment terms specified in the agreement or invoice.
• We accept various payment methods, including credit cards, bank transfers, and other payment gateways.
• Late payments may incur additional charges, and we reserve the right to suspend services for non-payment.

6. Project Scheduling and Delays

• Project timelines are estimates and may be subject to delays due to unforeseen circumstances such as weather, material availability, or other external factors.
• We will make reasonable efforts to communicate any delays and reschedule the project accordingly.
• Clients are responsible for ensuring that the worksite is ready and accessible for the scheduled work.

7. Client Responsibilities

• The client must ensure that the worksite is clear and prepared for the work to be performed.
• The client is responsible for providing access to the necessary utilities (electricity, water, etc.) if required.
• It is the client’s responsibility to ensure that all required permits, approvals, or other legal requirements are obtained before the commencement of work.

8. Warranty and Guarantee

• We provide warranties on our services and products, which vary based on the type of service performed. Specific warranty details will be provided in the service agreement.
• Our warranties cover defects in workmanship and materials for a specified period.
• We do not provide warranties for issues arising from misuse, neglect, or external factors beyond our control.

9. Limitation of Liability

• Concrete Surface Pros is not liable for any indirect, incidental, or consequential damages arising from the use of our services.
• Our liability is limited to the total amount paid for the service rendered.

10. Cancellation and Refunds

• Clients may cancel services by providing written notice at least [insert time period] before the scheduled service date.
• Refunds for canceled services will be issued according to the terms outlined in the service agreement or invoice.

11. Intellectual Property

• All content on our website, including text, graphics, logos, images, and software, is the property of Concrete Surface Pros and is protected by copyright and trademark laws.
• You may not use, reproduce, or distribute any content from our website without prior written consent.

12. Privacy Policy

Your use of our services is also governed by our Privacy Policy, which outlines how we collect, use, and protect your personal data. Please review the Privacy Policy for more details.

13. Governing Law

These Terms and Conditions are governed by and construed in accordance with the laws of [insert jurisdiction], and any disputes arising from the use of our services will be subject to the exclusive jurisdiction of the courts in that jurisdiction.

14. Changes to Terms and Conditions

We reserve the right to modify or update these Terms and Conditions at any time. Any changes will be posted on this page, and the updated terms will be effective immediately upon posting. It is your responsibility to review these terms regularly.

15. Contact Us

If you have any questions or concerns about these Terms and Conditions, please contact us:

Concrete Surface Pros
Email: info@concretesurfacepros.net
Phone: +1 507-625-7767
Address: 414 S Front St, Mankato, MN, United States, Minnesota

By using our website and services, you acknowledge that you have read and agree to these Terms and Conditions.